‘Concrete Contractor Agreement Template’ PDF Quick download link is given at the bottom of this article. You can see the PDF demo, size of the PDF, page numbers, and direct download Free PDF of ‘Sample Construction Contract’ using the download button.
Concrete Contractor Agreement Template PDF Free Download
Instruction Under Agreement
SCOPE OF WORK
The Contractor shall furnish all labor tools and equipment and do all things required for a complete installation, construction, and restoration of all disturbed areas in accordance with the plans and specifications.
The plans and specifications shall be on file in the office of the City Engineer. The cost of all work necessary to properly complete said work shall be included in the unit prices submitted by said contractor.
If the Subcontractor asserts a claim that involves, in whole or in part, acts or omissions that are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor’s claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and insufficient time for the Contractor to do so.
The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor that arise out of the Contractor’s submission of the Subcontractor’s claims to the Client or other responsible party(ies).
The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
X. Subcontracting. The Subcontractor shall have: (choose one)
☐ – Right to Subcontracting: Subcontractor may subcontract, either part or in whole, the Services authorized under this Agreement. The Subcontractor shall be required to obtain a written agreement from each subcontractor that is the same or comparable to the following Sections of this Agreement and to be approved, in writing, by the Contractor.
☐ – No Right to Subcontracting: Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.
| Author | – |
| Language | English |
| No. of Pages | 10 |
| PDF Size | 1 MB |
| Category | Forms PDF |
| Source/Credits | eforms.com |
Concrete Contractor Agreement Template PDF Free Download